Terms & Conditions

TERMS AND CONDITIONS OF SALE – COMMERCIAL CUSTOMERS

DEFINITIONS

“The Acknowledgement of Sale” means the Company’s acknowledgement in writing confirming the Agreement.

“The Agreement” means the Agreement between the Customer and the Company relating to (inter alia) the sale by the Company to the Customer of the Customer’s Equipment; the supply of the Company’s Equipment; the Works and the provision of the Services. This will include these Terms and Conditions, any quotation provided by The Company and any and all relevant documents which have been sent by The Company to The Customer.

“Additional Charges” means the charges for the Services or Works provided to the Customer by the Company that are not detailed within the Annual Maintenance Charge, Annual Monitoring Charge or Installation Charge. Additional Charges include for such parts and services (including the cost of travel) of the Company’s employees, agents and / or subcontractors. These charges relate to but are not limited to; (a) any labour, travel, materials or equipment requested or found necessary as a result of service repairs or modifications; (b) emergency call-outs; (c) any remote intervention, remote resets and technical telephone support provided; (d) any labour, travel, materials or equipment required as a result of any fault due to the Customer’s breach of this agreement; (e) any work or repairs (not falling within clause 3.5); (f) disposal of goods and / or materials; (g) return visits for the completion of the Services or Works; (i) abortive visits where the Company has been unable to complete the Services on initial attendance; (j) administration fees; (k) suspension and reinstatement fees and (l) civils work. For the avoidance of doubt, the foregoing events are specifically excluded from all service levels provided by the Company and are always chargeable.

“Annual Maintenance Charge” means the annual maintenance charge relating to the Services, as specified in the proposal issued to the Customer by the Company.

“Annual Monitoring Charge” means the annual monitoring charge relating to the Services, as specified in the proposal issued to the Customer by the Company.

“Charges” means all amounts payable by the Customer to the Company under or in connection with the Agreement for the provision of the goods and/or services, including (without limitation) all charges, fees, rates and sums relating to labour, supervision, engineering, design, project management, installation, commissioning, testing, maintenance, materials, components, plant, machinery, tools, equipment, software, hardware, consumables, transport, delivery, packaging, handling, storage, insurance, mobilisation, demobilisation, accommodation, subsistence, travel, permits, licences, third-party costs, subcontractor or supplier costs, administrative expenses, overheads, profit, variations, additional works, and any other costs, expenses or disbursements incurred by or payable to the Company in connection with the performance of the Agreement.

“Commissioning” means the engineering test to be carried out on and at the Site to the System to commission the System.

“The Company” means Mitie Security Limited, Company No. 01013210, Marlowe Fire & Security Limited – Company No. 05239777, Marlowe Kitchen Fire Suppression Limited – Company No. 08451949, Fire Alarm Fabrication Services Limited T/A FAFS Fire & Security & MRFS Group – Company No. 02565127, Alarm Communications Limited T/A ACL & Griffin Fire – Company No. 01804961, Morgan Fire Protection Limited – Company No. 02002176, Clymac Limited – Company No. 03019000 and Marlowe Smoke Control Limited – Company No. 06904844 whose Registered Office is Level 12, The Shard, 32 London Bridge Street, London, England, SE1 9SG, or any other holding company or subsidiary company or associated company under common ownership thereof, designated by the Company as the contracting party for the purposes of the Agreement who will provide the Service to the Customer.

“Company’s Equipment” means any and all equipment supplied by the Company to the Customer that has not been paid for by the Customer in full.

“The Customer” means the party receiving the Services or Works provided by the Company.

“Customer’s Equipment” means all equipment comprising the Works or System which has been supplied to the Customer by the Company and been paid for in full.

“Excluded Parts / Services” means; (a) all consumables including but not limited to; batteries, light sources, door contacts;

(b) obsolete equipment; (c) closed protocol equipment; (d) control equipment including panels and D/NVRs; (e) signalling equipment; (f) high level access equipment including scaffolding, lifters, cherry pickers and scissor lifts; (g) equipment damaged due to vandalism, misuse, force majeure, Acts of God and environmental issues including but not limited to, vermin, wildlife, storms, fire, flood and water damage; (h) breach by the Customer of their obligations under this Agreement and (i) the actions of third parties including but not limited to mains power failure and communications line faults.

“Installation Charge” means the Charges relating to the Works and System, as specified in the proposal issued to the Customer by the Company.

“The Installation / Takeover Date” means the date when the Works have been completed by the Company (which will be evidenced through written notification from the Company to the Customer) or the date from which the Company begins to maintain and / or monitor the System (which will be evidenced through written notification from the Company to the Customer).

“Normal Working Hours” means the hours between 08:30 to 17:00, Monday to Friday excluding Public Holidays.

“Premium” means the service level provided during the Term, whereby the Company in respect of the System: (a) undertakes the number of preventative maintenance visits set out in the proposal issued to the Customer by the Company on dates specified by the Company during Normal Working Hours; (b) provides an emergency help desk facility 24 hours per day, 365 days per annum basis to receive reports of faults on the System; (c) attends the Site without charge (with the exception of Excluded Parts / Services) within the time prescribed by the Response Level to diagnose reported faults; (d) carries out without charge (with the exception of Excluded Parts / Services) such maintenance work found necessary as a result of normal wear and tear; and (e) replaces without charge (with the exception of Excluded Parts / Services) any faulty component part of the System where the fault has arisen due to normal wear and tear. For the avoidance of doubt, only in exceptional circumstances, authorised, in writing by a Director of the Company, does the Company offer a Premium service level to a Customer. A Standard service level is the normal service level offered by the Company on a default basis to all Customers.

“Priority Response” means attendance within 4 hours or by the time the System is set (whichever is greater), on a 24 hours per day, 365 days per annum basis.

“Response Level” means the time scale for an engineer to attend to an emergency call-out being either Priority Response, Standard A Response or Standard B Response.

“Services” means any ongoing or periodic services provided by the Company under or in connection with the Agreement in relation to (but not limited to) fire protection, fire detection, life safety, security, and associated systems, including (without limitation) maintenance, servicing, inspection, monitoring, remote monitoring, system management, fault diagnosis, repair, replacement of components, upgrades, technical support, emergency call-out, and any other operational, preventative, or reactive support services required to maintain or manage such systems following completion of the Works or otherwise during the Term of the Agreement.

“The Site” means the Customer’s premises where the Services or Works are delivered.

“The Site Representative” means the Customer’s site representative who is technically competent and qualified and has specific knowledge of the Site.

“Standard” means the service level provided during the Term, whereby the Company in respect of the System: (a) undertakes the number of preventative maintenance visits set out as specified on the proposal issued to the Customer by the Company on dates specified by the Company during Normal Working Hours; (b) provides an emergency help desk facility 24 hours per day, 365 days per annum basis to receive reports of faults on the System; (c) undertakes to attend the Site on a chargeable basis to diagnose reported faults; (d) carries out on a chargeable basis, such repair work found necessary, replacing on a chargeable basis, any component part used in the course of the resulting maintenance work or any equipment where, in the Company’s sole opinion, repair of component parts would be uneconomic.

“Standard A Response” means attendance within 8 hours, on a 24 hours per day, 365 days per annum basis.

“Standard B Response” means attendance within the next working day during Normal Working Hours.

“The System” means the equipment as detailed in the System Specification / maintenance and / or monitoring proposal issued to the Customer as detailed in the proposal issued to the Customer by the Company.

“The Term” means the Initial Term as specified in clause 8.1 as extended in accordance with clause 8.2.

“Works” means any project-based works to be carried out by the Company under or in connection with the Agreement relating to (but not limited to) fire protection, fire detection, life safety, security, and associated systems, including (without limitation) the supply, installation, integration, configuration, programming, commissioning, testing, inspection, and certification of equipment, devices, infrastructure, cabling, software, or systems, together with any associated site works, project management, engineering, and ancillary activities necessary for the completion of such installation or project works.

1. EXCLUSIVE TERMS OF THE AGREEMENT

1.1 This Agreement sets out the conditions upon which the Company provides the Customer with the Services or Works. This supersedes any previous discussions, arrangements or representations between the Company and the Customer. Other information provided by the Company should only be used as a guide and may be subject to periodic amendment reflecting changes to the systems and services offered by the Company or errors or omissions contained in the Company’s literature. Any variations to this Agreement will only become binding upon the Company, if agreed in writing by a Director of the Company. Nothing in this Agreement shall have the effect of depriving the Customer of its rights in respect of any fraudulent misrepresentation.

1.2 The Company reserves the right to refuse to accept any order based upon a proposal more than 30 days old in age unless otherwise stated in the proposal to be open for a longer period and the proposal has not been withdrawn by the Company in that period.

1.3 Where the order for Customers Equipment is based upon the standard price list of the Company the price shall be valid provided that delivery is to take place within 30 days of the date of order. Should delivery exceed this period then the Company reserves the right to amend their proposal.

2. CUSTOMER OBLIGATIONS

2.1 The Customer shall:

2.1.1 Obtain and pay for all necessary consents for the Services or Works. The Customer warrants that all consents and licences required for the Services or Works on the terms of this Agreement will have been obtained prior to commencement of the Agreement.

2.1.2 Give to the Company such access to the Site as is reasonably required at all reasonable times in order for the Company to install the Works, provide the Services and / or exercise its rights hereunder. The Customer warrants that it is and shall be entitled (at all times that are relevant for the performance of the parties rights and obligations under this Agreement) to grant such access. In the event of such access not being made available by the Customer then the Company may charge the Customer an abortive visit charge at its standard rates.

2.1.3 Ensure that there are suitable power supplies for hand-tools, adequate lighting, toilet and rest facilities, secured facilities for the storage of plant and machinery necessary to carry out the Agreement and an acceptable and safe working environment.

2.1.4 In the specific case of monitored Systems;

2.1.4.1 pay to the communications service provider such charges as may be made by the communications service provider for the connection of the System to the service provider’s communications network and for any maintenance charges levied by the communications service provider;

2.1.4.2 agrees to ensure that any changes in respect of the System configuration, keyholder Information, passwords and other important information, is communicated to the Company in writing, immediately or uploaded to the Company’s portal. The Customer acknowledges that the Company has no obligation to contact a Keyholder if the details of that Keyholder are incorrect or have been changed but not notified to the Company;

2.1.4.3 take all reasonable steps to prevent false activations being transmitted to the Company. The Customer warrants that in the event of false activations, which in the sole opinion of the Company are deemed excessive, the Company may;

2.1.4.3.1 levy; additional charges to the Customer for the work resulting from such false activations transmitted by the System,

2.1.4.3.2 suspend all or part of the Services offered to the Customer;

2.1.4.3.3 charge the Customer a disconnection and reconnection fee for the disconnection and reconnection of the Services;

2.1.4.3.4 terminate the Agreement in whole or in part should the false activations continue without address by the Customer. In such instances, the Company will advise the Customer as soon as is practicably possible – confirming this in writing the next working day – of the extent that the Services has been limited or suspended. For the avoidance of doubt, the Customer will not be entitled to any refund for the suspension or restriction of the Services;

2.1.5 Not (and shall not permit any other person other than the Company and its duly authorised agents to) remove, repair or replace or in any way interfere with the System or any part of it.

2.1.6 Notify the Company of any proposed structural alterations to the Site or of any modifications to the communications installation so that the Company may assess whether such works will affect the Services or the Works. Any such extension or alteration to the Services or Works, which may thereby become necessary, shall be carried out by the Company at the expense of the Customer.

2.1.7 Notify the Company forthwith (confirming such notification in writing) of any defects appearing in the System and shall permit the Company to take such steps as it shall consider necessary to remedy such defect.

2.1.8 Bear the cost of replacing any part of the System which is; defective, damaged, destroyed, lost or stolen. The decision to replace any part of the System is at the sole discretion of the Company.

2.1.9 If the System requires a Unique Reference Number (URN), pay the prevailing fee to the relevant Police Authority for the application and / or amendment and / or transfer of the URN.

2.1.10 Comply with such instructions as shall be provided with the System or as the Company shall from time to time reasonably issue.

2.1.11 Take all reasonable precautions to protect the health and safety of the Company’s employees, agents and sub-contractors while on the Site.

2.1.12 Make available the System and supply all documentation and other information necessary for the Company to diagnose any fault in the System.

2.1.13 Maintain and make available to the Company an up to date Fire Risk Assessment compliant with the Regulatory Reform (Fire Safety) Order 2005.

2.1.14 Buy the Customer’s Equipment on the terms of this Agreement.

2.1.15 Maintain (through utilisation of the Services) the System in good working order to the Company’s satisfaction.

2.1.16 Ensure the availability of an appropriate power supply through supply/installation of fuse spurs including 240 volt AC 13 amp unswitched fused spur supplies to be provided adjacent to the proposed panel/charger/control location/s which must be certificated to the current edition of the IEE Wiring Regulations.

2.1.17 Ensure the availability of a subscriber terminal unit / communication portal and any other necessary communication line to enable monitoring.

2.1.18 Be responsible for financing the collection, treatment, recovery and environmentally sound disposal of all waste including but not limited to WEEE arising or deriving from the Services or the Works and will comply with all additional obligations placed upon the Customer by the WEEE Regulations by virtue of the Customer accepting the responsibility set out above.

2.1.19 Provide a duly authorised Site Representative empowered to sign the Company’s paperwork to evidence the Services or Works was provided by the Company to the Customer’s satisfaction. Should the Customer fail to provide a duly authorised Site Representative at the time of the Company’s attendance then the Customer is deemed to have accepted the delivery of the Services or Works is full and to their complete satisfaction.

2.2 The Customer acknowledges and accepts that:

2.2.1 Before the Services commences, the Customer agrees to cooperate with the Company and undertake such tests as may be requested to test that the System is properly connected / installed so that the Services can commence and be delivered.

2.2.2 Should the Company determine that the circumstances of an activation or series of activations appear such that the Company wishes to contact a Keyholder, the Company will attempt to contact a minimum of two Keyholders and will make one attempt to telephone each Keyholders’ primary contact telephone number and one attempt to telephone any alternative contact number listed for that particular Keyholder. Where a Keyholder is not contactable, the Customer agrees and accepts that it shall be sufficient to leave a message on the Keyholders’ answering service or device or with the person answering the call. The Customer must also provide a primary e-mail address for reporting purposes. It is the Customer’s responsibility to provide the Company with full and correct contact details for all nominated Keyholders.

2.2.3 The Company has no obligation to contact a Keyholder if the details of that Keyholder are incorrect or have been changed but not notified to the Company.

2.2.4 Where the System comprises of an intruder alarm system, the Company has brought to the Customer’s attention the requirements of the prevailing policy of the National Police Chiefs’ Council (NPCC) policy on Police response to security systems.

2.2.5 Where the System comprises of a CCTV system, the Company has brought to the Customer’s attention the requirements of the Data Protection Act in respect of CCTV monitoring.

2.2.6 Where the System comprises of any other security or fire safety system the Company has brought to the Customer’s attention the requirements of the relevant British and European Standards and Legislation.

2.2.7 For the purpose of the Service or Works, the Company require that any Customer plant or machinery provided to us (for our use) and used during the course of the Service or Works, that the Customer shall hereby indemnify the Company against any loss or damage arising from the activities undertaken unless such act is solely caused by our negligence or wilful misconduct. All plant and machinery will be subject to formal and recorded inspection prior to its use and when required service and maintenance records will be provided upon request with the Customer solely responsible for ensuring the equipment used is fit for purpose and in line with any regulatory inspection. If it is identified that any equipment provided for works is found to be maintained in an unsatisfactory condition, then any loss or liability during works will remain solely with the Customer. If there is any reason or condition where these terms cannot be accepted, the Company will provide the required plant or machinery against which reasonable charges will be applied.

3. OBLIGATIONS OF THE COMPANY

3.1 The Company shall;

3.1.1 sell the Customer’s Equipment to the Customer;

3.1.2 provide the Works as specified in the proposal issued to the Customer by the Company and

3.1.3 during the Term provide the Services.

3.2 The Company reserves the right to substitute equipment (either at the time of original installation or at replacement) detailed on the specification for any reason, providing it affords, materially, the same degree of functionality as the original items specified, having regard to the System as a whole.

3.3 No Services or Works will be carried out outside Normal Working Hours unless the Customer agrees to pay additional charges to the Company at the Company’s then prevailing rates for such work at such times. Unless previously specified, no external work (whether in respect of installation or the provision of preventative or corrective maintenance services) shall be undertaken after ‘local lighting up time’ even if during Normal Working Hours, unless adequate and safe lighting, to the satisfaction of the Company, is provided by the Customer at the Customers own cost.

3.4 The cost of delivery of the Customers Equipment shall be an Additional Charge unless advised otherwise. Any other method of delivery or any special packaging requirements must be specified by the Customer at the time of the order and shall be an Additional Charge.

3.5 The Company will warrant any equipment comprising the Customer’s Equipment (whether a part as originally installed in the Works or a replacement part supplied during the Services) for a period of twelve months from the date it was installed (the correction period). At the Company’s discretion, this warranty includes for labour relating to the removal and replacement of such goods during this period. In addition, warranty of all systems is subject to maintenance to current British Standards by the Company throughout the correction period. For the avoidance of doubt the cost of replacement of any parts (whether replacement or otherwise) that fail outside the correction period shall be chargeable to the Customer unless otherwise provided for under these conditions. The Customer must give written notice to the Company within 28 days after the appearance of any defect. Should the Company agree to provide an extended warranty to the Customer’s Equipment, this extension must be in writing and for the avoidance of doubt will exclude labour relating to the removal and replacement of goods which will be chargeable by the Company to the Customer at the Company’s prevailing rates.

3.6 The attendance of the Company’s Commissioning Engineer to the Site whether to carry out repairs, investigate reports of false alarms or faults on the Customers Equipment whether supplied, installed or commissioned, caused by misuse, damage, neglect or vandalism will be charged as an Additional Charge and shall be at the cost of the Customer at the Company’s prevailing rates. Where any Customers Equipment is returned to the Company for repairs then unless otherwise agreed the Customer shall be responsible for the costs of carriage, to the Company.

3.7 The Company will use all reasonable endeavours to meet installation timetables and Response Levels but shall not be responsible for any loss suffered as a result of a failure by the Company to comply with time obligations under this Agreement. The Customer further accepts that some faults may not be capable of immediate correction by the Company. Any delays shall not entitle the Customer to rescind the Agreement.

3.8 The Customer warrants that it has drawn to the attention of the Company all factors affecting the Site which may affect the method of installation, specification of the Works and the provision of the Services.

3.9 Unless stated in the proposal or the Acknowledgement of Sale all prices for installation are based on the assumption that the Customers Equipment will be surface fixed. Any additional work required to install the Customers Equipment or to achieve a flush installation shall either be provided by the Customer at its cost, including any redecoration that may be necessary or shall be an Additional Charge. Unless otherwise specified in the proposal or the Acknowledgement of Sale the Company shall not be obliged to reinstate or make good any part of the Site which may be affected by the installation.

3.10 Unless stated in Company’s proposal or the Acknowledgement of Sale no allowance has been made for (a) the provision of as installed drawings (b) any inter- connection of the Customers Equipment to any other system or equipment at or on the Site. The provision of these will incur Additional Charges.

3.11 Where the Customers Equipment is required to meet a particular level of audibility, whether relating to an identified level of clarity or minimum volumes, the Company accepts no liability to comply with these requirements when the quantities and/or location of Customers Equipment has been instructed by a third party, whether as detailed on layout drawings or equipment schedules or otherwise. If required the Company’s Commissioning Engineer will carry out a full audibility test on completion of the installation and report on any defect as an Additional Charge. The cost of any work involved in raising the level of audibility shall be an Additional Charge.

3.12 Unless specifically stated in the proposal, the Company have not included for systems that use voice alarms, to have their speech intelligibility confirmed via RASTI Testing. Where such tests have been specifically included and documented in the proposal, they will be carried out only after full on site tests, which will need to be carried out after the main structural works have been completed. Only after these tests will the Company be in a position to advise on final speaker quantities, locations and sizes. This in turn may affect cabling requirements and amplifier sizes which will be an Additional Charge.

3.13 At all times, the Company will operate in accordance with General Data Protection Regulations and its requirements in relation to the secure management of the Customer’s data.

4. COMMISSIONING

4.1 Where the Customers Equipment to be commissioned has not been installed by the Company, the Customer will be required to provide on the Site for the period of Commissioning, a Site Representative.

4.2 Before the Company’s Commissioning Engineer will commence any connection or testing work as part of the commissioning, the Customer must issue to the Commissioning Engineer for retention a complete set of all cable test sheets which must detail as a minimum the information required under the then current IEE Regulations.

4.3 Where the Commissioning involves fire alarm systems, any documents not available to the Commissioning Engineer, will be recorded on the certificate as being a variation from BS 5839 Part 1.

4.4 The Commissioning Engineer will carry out low voltage continuity earth line resistance and capacitance tests on all circuits as part of the Commissioning and any failures will be notified to the Site Representative who will be required to instigate the clearance of these faults.

4.5 The Commissioning Engineer must be satisfied prior to commencement of Commissioning that all cables are clearly marked and identifiable as well as all conductors. With particular regard to Commissioning involving fire alarm systems all cables and conductors must be appropriately identified and if not this will be recorded on the certificate as a variation from BS 5839 Part 1.

4.6 In the event of any delay of Commissioning and which is not due to the failure of the Company and whether caused by the Customer or otherwise, the Company retains the right to charge as an Additional Charge for either an abortive visit or for the additional hours incurred in waiting for the faults to be rectified. Any such Additional Charge will be charged at the then hourly rate for Commissioning services. In addition, any time lost due to lack of access to the site on the pre-arranged day, incomplete works, unavailable access equipment or lack of installed drawings will be charged as an Additional Charge.

4.7 The Commissioning Engineer will provide a separate docket covering the additional time involved in Commissioning which must be signed by the Site Representative. The failure by the Customer to acknowledge and accept these charges as they are incurred will result in the Commissioning Engineer not returning to the Site to complete the works.

4.8 The cost of Commissioning only includes the final connection of any control Customers Equipment. All Customers’  Equipment must be connected by the time the Commissioning Engineer attends the Site. If any cables are to be terminated by the Commissioning Engineer then these must, where applicable, be glanded off and stripped ready for termination.

4.9 No detector heads are to be installed by the Customer until the Commissioning Engineer has carried out his own particular test to the respective circuits. The Customer shall be responsible for the fitting of the detection head once the Commissioning Engineer is satisfied. As far as the fitting of detector heads is concerned, the Commissioning Engineer will only be involved in the setting of detector address prior to installation. Where protective covers are provided as part of the original packaging, this must be left in place until removed by the Commissioning Engineer.

4.10 The Customer will be required to provide all analogue and addressable systems programming data at least 10 working days prior to commissioning. The failure by the Customer to provide such data may delay the Commissioning for which the Company will not be liable. The delay in providing this data may also require the Commissioning Engineer to make an additional visit or visits for which an Additional Charge may be charged.

4.11 The Customer is responsible for and required to make available to the Commissioning Engineer all installed drawings and zone charts for specific schematic drawings. If requested at the time of commencement of commissioning, the Commissioning Engineer will during such Commissioning be prepared to assist to ensure that on addressable systems the correct address numbers are provided for inclusion on their own as installed drawings.

4.12 Any Customers Equipment supplied by the Company which is to be commissioned will be tested in the presence of the Site Representative.

4.13 The Customer is required to give at least 10 working days’ notice for the attendance of the Commissioning Engineer.

4.14 Commissioning allows for one final handover to the Customer. In the event the Customer requires any third party to be present to approve the Commissioning then the Customer must arrange and any additional visit required to demonstrate the system to any third party will be an Additional Charge.

5. THE COMPANY’S LIABILITY

5.1 The provisions of this clause set out the Company’s entire liability (including any liability for the acts and omissions of its employees or sub contractors) to the Customer in respect of any breach of its contractual obligations arising under the Agreement and any representation, statement or tortuous act or omission – including but without limit, to negligence or breach of statutory duty – arising under or in connection with the Agreement and the Customer’s attention is in particular drawn to the provisions of this clause.

5.2 In view of the limitations of the Works and the Services and the provisions of this clause, the Customer will arrange separate insurance cover.

5.3 Any act or omission on the part of the Company or its employees, agents or sub-contractors falling within clause 5.1 shall be known as an ‘Event of Default’.

5.4 Subject to clauses 5.5 and 5.6 the Company will not be liable for any loss, damage or injury sustained by the Customer or his property unless directly caused by the negligence of the Company or its employees.

5.5 Subject to the provisions of clause 5.6 the entire aggregate liability of the Company its employees agents and subcontractors in respect of any Event of Default shall be limited to a maximum sum equivalent to 100% of the total Installation Charge or 3 times the sum of the Annual Maintenance Charge or Annual Monitoring Charge – whichever is the lower – (in each case as at the date of the Event of Default, if known, otherwise, as at the date of notification of the claim to the Company). There will be no liability on behalf of the Company if the relevant invoice from the Company has not been paid by the Customer prior to the Event of Default.

5.6 The Company does not restrict its liability in respect of death or personal injury resulting from its own or that of its employees agents or subcontractors negligence or any damage suffered by the Customer where it would be unlawful to do so.

5.7 Subject to clause 5.6 the Company shall not be liable to the Customer in respect of any Event of Default for loss of profits, goodwill or any type of special, indirect, uninsured or consequential loss (including loss or damage suffered by the Customer as a result of action brought by a 3rd party) even if such loss was reasonably foreseeable or the Company had been advised of the possibility of the Customer incurring the same.

5.8 If a number of Events of Default give rise substantially to the same loss then they shall be regarded as giving rise to only one claim under this Agreement.

5.9 The Customer shall afford the Company (if it shall so request) a reasonable time in which to remedy any Event of Default.

5.10 Without prejudice to the generality of the foregoing the Company shall not be liable for;

5.10.1 any failure of the System to transmit data from the site;

5.10.2 any failure in the telecommunications network, telephone lines, power supplies, utilities or other services provided by a service provider or utility or any other condition beyond the Company’s control that prevents the System from in any way performing or the Company from being able to perform part or all of the Works or Services and / or secure attendance of a Keyholder or the Emergency Services to the site;

5.10.3 any breach of contract due to any cause beyond its reasonable control including but not limited to; force majeure, Acts of God, war, military actions, sabotage, terrorist actions, riots, civil disobedience, strikes, industrial action, civil disaster, floods, lightning, epidemics, fire and acts or omissions of any party for which the Company is not responsible;

5.10.4 any loss, damage, costs, expenses or any other claims for compensation arising from incomplete, inaccurate or corrupted data transmissions being received by the Company and

5.10.5 any loss, damage, costs, expenses or any other claims for compensation arising from delays in Works or Services provision caused by circumstances beyond the control of the Company.

5.10.6 any loss, damage, costs, expenses or any other claims for compensation arising from carbon offset, carbon refill, or carbon escape costs in relation to gas suppression.

5.11 The Customer acknowledges that;

5.11.1 the Company has no special knowledge of the nature and value of the contents of the Site or of the nature of the risks to which the Site and its contents will be exposed;

5.11.2 the System,the Services and the Works are only an aid to security and fire safety and are designed to reduce the risk of loss or damage to the Site, its contents and occupants but does not guarantee to eliminate any part of such risk. The Company does not warrant or guarantee that the System or the Services will prevent, deter or restrict fire or trespass on the site or damage or criminal actions against the Site, its contents or occupants. The Company does not warrant or represent that the System or the Services is incapable of being compromised, neutralized bypassed or otherwise rendered inoperative by the Customer, trespassers, intruders or other unauthorized persons. In such event the Company shall not be liable for direct or indirect loss or damage suffered by the Customer, occupants, intruders or other unauthorised persons and the Customer acknowledges and agreed to the limitations of the Company’s liability in relation to this clause;

5.11.3 the effectiveness of the System and / or Services or Works is limited to the configuration of the System on the Site. As such, the System may suffer from areas of reduced detection, which can result in fire and intrusions not being detected by the System. Furthermore, changes in atmospheric conditions can result in changes in the effective operating range of detection devices, creating transient ‘blind spots’;

5.11.4 the provision of the Services or Works will not guarantee that the System will operate without interruption or error.

5.12 The Customer agrees to immediately advise the Company by telephone and in writing within 48 hours, to be delivered to the Company by registered mail, details of any incident or complaint regarding the System or the Services to enable the Company to investigate the incident or complaint. In the event of the Customer making a claim against the Company for loss or damage, the claim must be made within 21 days of the occurrence specifying in detail the quantum and the basis of the claim. The Company shall have no liability for any claim made outside this period.

5.13 If the System should fail, due to a faulty part, which has not been supplied or manufactured by the Company, the Company shall have no liability for such failure.

5.14 The Customer shall be responsible for and reimburse the Company for any charges made by the Police, Fire or any other authority to the Company in connection with the Works and/or Commissioning of the System.

6. ACCEPTANCE

6.1 Once the Company has commenced Works or has started to provide the Customer with the Services, or on payment in part or in full for the Works or the Services, the Customer acknowledges they have accepted the entire terms and conditions set out in this Agreement.

6.2 The Customer may (with the Company’s prior written consent) cancel the Agreement before the Installation / Takeover Date. In the event of such cancellation the Company shall be entitled to levy a cancellation charge (which shall become payable immediately by the Customer) at the rate of 25% of the Installation Charge or 50% of the Annual Maintenance Charge and / or 50% of the Annual Monitoring Charge together with all restocking charges incurred by the Company.

7. PAYMENT

7.1 In consideration of the Works provided to the Customer by the Company, the Customer will;

7.1.1 pay 50% of the Installation Charge on issue of order to the Company and 50% on the Installation / Takeover Date or agree with the Company, at the Company’s sole discretion, to pay 50% of the Installation Charge on issue of order to the Company and then pay the remaining 50% of the Installation Charge in interim payments (minimum monthly), to the Company;

7.1.2 In consideration of the Services provided to the Customer by the Company, the Customer will;

7.1.3 pay 100% of the Annual Maintenance Charge and / or 100% of the Annual Monitoring Charge prior to the Installation / Takeover Date and each subsequent years’ Annual Maintenance Charge and / or Annual Monitoring Charge, prior to the commencement of the period to which the invoice relates;

7.1.4 pay (at the Company’s prevailing rates) all Additional Charges upon receipt of the Company’s invoice

7.1.5 pay all invoices received from the Company within 30 days (default payment terms)

7.1.6 any advance payments that the Company has requested from the Customer must be made at least 14 days prior to commencement of the works.

7.2 The Company may, at its sole discretion, allow payment of the Annual Maintenance Charge by instalment. Should the Company permit payment of the Annual Maintenance Charge by instalments and any instalment is not paid then the total amount of the Annual Maintenance Charge (including the instalment surcharge) will become immediately due and payable.  

7.3 All sums due by the Customer to the Company under the Agreement shall be paid without any set-off (whether legal or equitable) deduction or withholding of any kind.

7.4 The Company will not accept as a reason for non-payment any defects arising from the Works, which have not been notified in writing to the Company within 14 days of the Installation / Takeover Date.

7.5 If the Customer fails to make any payment as and when it becomes due, the Company shall be entitled to do all or any of the following (in any order and on more than one occasion and such rights shall be in addition to any the Company shall have at law);

7.5.1 cancel or suspend all or any part of the Services or Works without incurring any liability and without prejudice to the Company’s rights to collect and levy the charges for such services. Cancellation and / or suspension and reinstatement of monitoring will lead to a fee being charged at the Company’s then current rate; and

7.5.2 charge the Customer interest (both before and after any judgement) on unpaid sums – beyond their due date – at the rate of 8% per month, compounded monthly, until payment is made in full.

7.6 All costs, charges and expenses incurred by the Company (including legal and court costs) in recovering or attempting to recover any debt shall be paid by the Customer on a full indemnity basis. The Company shall be entitled to charge (in addition to interest and any legal costs ordered by the court, and without prejudice to any other rights or remedies available to the Company) the sum of £150 (excluding VAT) by way of notional liquidated damages and as a contribution to the administrative costs incurred by the Company in taking steps to secure overdue payment. The provisions of this clause shall apply notwithstanding any termination or cancellation of this Agreement.

7.7 Any addition or variation to the quantities of assets or components, which comprise the System, may, at the Company’s sole discretion, result in an increase to the Annual Maintenance Charge, Annual Monitoring Charge and Additional Charges. 

7.8 In addition the Company is entitled (at any time) to increase the Annual Maintenance Charge, Annual Monitoring Charge, Additional Charges and Charges by giving written notice (which may be in the form of the invoice) of such increase to the Customer.

8. TERM

8.1.1 Where Service is to be provided, the initial term of this Agreement is five years commencing from the Installation / Takeover Date.

8.1.2 Where Works are to be provided, the Works will be carried out and completed in a reasonable timeframe.

8.2 At the end of the initial term and each subsequent period, the Term will be automatically renewed for a further 12 months unless the Company or the Customer has given the other written notice of its wish to terminate the Agreement at least 60 days before the end of the then current Term.

8.3 If the Agreement is not terminated in accordance with these terms, then the Customer shall make payment of the Annual Maintenance Charge and / or Annual Monitoring Charge for the additional Term prior to the expiry of the current Term to avoid incurring the administration charges and ongoing interest upon sums due to the Company.

8.4 If the Customer wishes to cancel the Agreement before the end of the Term and without giving notice in accordance with clause 7.2, then the Customer shall;

8.4.1 pay to the Company on demand all arrears of the Annual Maintenance Charge and / or Annual Monitoring Charge and any Additional Charges that would have been made by the Customer for the remainder of the duration of the Term;

8.4.2 indemnify the Company against any additional loss costs charges and expenses incurred by the Company as a result of such cancellation;

8.4.3 pay the Company a one off fee of £150 (excluding VAT) to attend Site and reset the System to enable the System to be handed over to the incoming service provider.

8.5 On termination of this agreement, the Customer will give the Company access to the Site to remove the Company’s Equipment and the Customer shall make good the Site at its own expense. If the Customer should fail to provide such access within 14 days of the Company’s written request the Customer shall pay to the Company an amount, by way of liquidated damages, equal to the cost to the Company of acquiring equivalent equipment.

8.6 If the Customer commits any breach of this Agreement or enters into any form of Liquidation, Administration, Receivership, Corporate Voluntary Arrangement, Individual Voluntary Arrangement or Bankruptcy, or any payment shall be more than one month in arrears, the Company may forthwith, by notice in writing, terminate this Agreement (and on such termination the Term shall come to an end) without prejudice to the Company’s right to recover all of the Company’s Equipment and any sum due by the Customer to the Company.

8.7 If the Company shall terminate this Agreement under clause 8.6 the Customer shall be liable to pay to the Company all sums then due together with all such other sums which would have become due in respect of the Annual Maintenance Charge and / or Annual Monitoring Charge from the date of termination to the earliest date upon which the Customer could have terminated this Agreement under clauses 8.1 and 8.2.

9. RISK AND TITLE

9.1 Risk of damage to or loss of the System and the requirement to insure the equipment shall pass to the Customer at the time of delivery to the Site.

9.2 Title to the Customer’s Equipment shall not pass to the Customer until the Company has received payment in full in cleared funds, of the Installation Charge of the System together with any charges levied under the terms of Clause 6. Including for any interest and administrative charge applied.

9.3 Until such time as title to the Customer’s Equipment passes to the Customer, the Customer shall hold the Customer’s Equipment as the Company’s fiduciary agent and bailee.

10. TECHNICAL INFORMATION/ADVICE

10.1 Any technical information supplied by the Company shall only be relied upon by the Customer if confirmed in writing by the Company. The Company is not liable for any such technical information provided verbally by its employees. The Company relies upon the information supplied by the manufacturer of the Customers Equipment and shall wherever so practicable supply the Customer if so requested with copies of the manufacturer’s technical information.

11. DISPUTE RESOLUTION

11.1 If any dispute arises in connection with the Agreement, an authorised representative of the Customer and the Company shall, within 30 days of a written request from one party to the other, meet in good faith to resolve the dispute.

11.2 If the parties fail to reach agreement by the conclusion of the mediation in accordance with 11.1 then the parties shall be free to refer to adjudication in accordance with the Scheme for Construction Contracts or commence formal legal proceedings in the courts in relation to the dispute. Nothing in this Clause shall prevent a party seeking urgent relief from the courts where it considers this is necessary to protect its position.

12. GENERAL

12.1 The parties to the Agreement are the Company and the Customer. Any obligation of the Company under the Agreement is to the Customer only and to no other party. Where any payments are made or undertaken by a third party, such payments or undertakings do not confer any rights on the third party who is considered an agent of the Customer.

12.2 The Agreement may not be assigned or held on trust by the Customer without the prior written consent of the Company. The Company may assign all or any of its rights hereunder.

12.3 The Company shall be entitled to subcontract any of its obligations under the Agreement.

12.4 The Company reserves the right to make changes to the Services or Works, in order to comply with safety, statutory or BS/EU requirements or codes of practice, provided that such changes do not materially change the Services or Works provided to the Customer.

12.5.1 The Company reserves the right to adjust the Charges at any time to reflect increases in the Company’s costs arising from factors outside its reasonable control, including but not limited to increases in the cost of labour, materials, components, energy, transport, storage, insurance, duties, taxes.

12.5.2 In addition, the Charges shall automatically increase on each anniversary of the Installation / Takeover Date by a percentage not less than the increase in the Retail Prices Index (RPI) published by the Office for National Statistics (or any replacement index).

12.5.3 The Company shall also be entitled to adjust the Charges where any change in law, regulation, standards, or statutory requirements occurring after the commencement of the Agreement results in an increase in the cost of performing the works or supplying the goods. The Company shall give written notice of any such adjustment and the revised price shall apply to all remaining goods or services to be supplied under the Contract.

12.6 Invalidity or unenforceability of any of the conditions in the Agreement shall not prejudice the remainder of the conditions of the Agreement.

12.7 Failure by the Company to exercise any right or remedy available to it under the terms of this Agreement shall not constitute a waiver of such right or remedy or any other rights or remedies and no partial exercise of any right or remedy shall prevent any further exercise of any right or remedy or the exercise of any other rights or remedies.

12.8 The Company shall have the right to vary these terms and conditions by notice to the Customer and the Customer shall be deemed to have accepted such new terms unless it has objected to the variations in writing within 14 days of such notice. If the Customer so objects, the Company shall be entitled to terminate this Agreement and if the Company does so terminate the Agreement it shall be entitled to full payment of any outstanding invoices which must be paid in full by the Customer without any right of set-off whatsoever, within 14 days of the said notice of termination by the Company.

12.9 No person who is not a party to this Agreement, save a company within the same group of companies or an associated company under common ownership as the Company, shall be entitled to enforce any term of this Agreement.

12.10 The Customer undertakes to indemnify and hold harmless the Company against any loss or damage the Customer may suffer as a result of a breach by the Customer of its obligations hereunder.

12.11 The Agreement shall be governed by and construed in accordance with English law. Each party irrevocably submits to the exclusive jurisdiction of the courts for the hearing and determination of any suit actions or proceedings that arise out of or in connection with this Agreement.

12.12 The Customer and the Company shall keep in strict confidence all technical or commercial know-how, specifications, inventions, processes or initiatives which are of a confidential nature and have been disclosed to one by the other, its employees, agents or subcontractors, and any other confidential information concerning either party’s business or its products or its services which either party may obtain. Both parties shall restrict disclosure of such confidential information to such of its employees, agents or subcontractors as need to know it for the purpose of discharging their obligations under the Agreement and shall ensure that such employees, agents or subcontractors are subject to obligations of confidentiality corresponding to those which bind the parties. This Clause [12.11] shall survive termination of the Agreement.